SOLICITATION NOTICE
C -- Sole Source Procurement for Pinnell/ Busch for Schedule and technical Analysis Assement for Contract NAFDS3-99-C-0029 Picatinny Aquatic Center Park Project, New Jersey
- Notice Date
- 8/11/2004
- Notice Type
- Solicitation Notice
- NAICS
- 541310
— Architectural Services
- Contracting Office
- US Army Engineer District, Seattle, ATTN: CENWS-CT, PO Box 3755, Seattle, WA 98124-3755
- ZIP Code
- 98124-3755
- Solicitation Number
- W912DW-04-Q-0147
- Response Due
- 8/12/2004
- Archive Date
- 10/11/2004
- Point of Contact
- Patricia Ortiz, 206 764-3516
- E-Mail Address
-
Email your questions to US Army Engineer District, Seattle
(patricia.a.ortiz@usace.army.mil)
- Small Business Set-Aside
- Total Small Business
- Description
- This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; proposals are being requested and a written solicitation will not bProvide professional schedule and claims analysis services for the following Military Project as administered by the Seattle District: Contract No. NAFDS3-99-C-0029, Design-Build Aquatic Center, Pic atinny, New Jersey. Base Bid Item 0001 - The Contractor shall provide a complete, detailed and independent analysis of construction schedule delays to determine entitlement to alleged impacts presented by Imperial Construction and Electric, Inc., by reviewing sundry contract documents located within Office of Counsel, Seattle District. A summary of findings shall be provided in both hard copy (qty 2) and electronic format as directed by the Contracting Officer??????s Representative (COR). Provide professional schedule and cla ims analysis services for the following Military Project as administered by the Seattle District: Contract No. NAFDS3-99-C-0029, Design-Build Aquatic Center, Picatinny, New Jersey. Base Bid Item 0001 - The Contractor shall provide a complete, detailed and independent analysis of construction schedule delays to determine entitlement to alleged impacts presented by Imperial Construction and Electric, Inc., by reviewing sundry contract documents located within Office of Counsel, Seattle District. A summary of findings shall be provided in both hard copy (qty 2) and electronic format as directed by the Contracting Officer??????s Representative (COR). Bid Item 0002 - The Contractor shall provide a separate, comprehensive Technical Analysis Assessment Report in support of work being performed by the Defense Contract Audit Agency (DCAA). The assessment shall address the allegations and nature of delays, issues of entitlement, inefficiency/loss factors, and provide a comprehensive cost estimate for delays having merit. The report shall be prepared in a format as directed by the COR, and submitted in both hard copy (qty 2) and electronic format. Optional Item 0003 ?????? The Contractor shall serve as an expert witness in support of legal proceedings as delineated by Government Counsel and at the direction of the COR. Proceedings are schedule to occur 26 October through 3 November 2004, at Falls C hurch, Virginia. Exercise option no later than 15 October 2004.
- Place of Performance
- Address: US Army Engineer District, Seattle ATTN: CENWS-CT, PO Box 3755 Seattle WA
- Zip Code: 98124-3755
- Country: US
- Zip Code: 98124-3755
- Record
- SN00641676-W 20040813/040811212559 (fbodaily.com)
- Source
-
FedBizOpps.gov Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |