DOCUMENT
58 -- CARROLLTON COUNTY WARRS RADIO SYSTEM - Attachment
- Notice Date
- 8/24/2012
- Notice Type
- Attachment
- NAICS
- 334290
— Other Communications Equipment Manufacturing
- Contracting Office
- Department of Veterans Affairs;Atlanta VA Medical Center;1670 Clairmont Road;Decatur GA 30033
- ZIP Code
- 30033
- Solicitation Number
- VA24712I1056
- Response Due
- 8/30/2012
- Archive Date
- 10/29/2012
- Point of Contact
- Jamal Carter
- E-Mail Address
-
1-6111
- Small Business Set-Aside
- Total Small Business
- Description
- THIS IS A SMALL BUSINESS SOURCES SOUGHT NOTICE REPRESENTING A MARKET SURVEY AND IS NOT A REQUEST FOR PROPOSALS, PROPOSAL ABSTRACTS, QUOTATIONS OR INVITATION FOR BIDS The Department of Veterans Affairs is conducting a sources sought to obtain information regarding: (1) the availability and capability of qualified small business sources; (2) whether they are Service-Disabled Veteran-Owned, Veteran-Owned, Small Business, HUB Zone 8(a), Women-Owned, or small disadvantaged business concerns; and (3) their size classification relative to the North American Industry Classification System (NAICS) code for the proposed acquisition. Your responses to the information requested will assist the Government in determining the appropriate acquisition method, including whether a set-aside is possible. An organization that is not considered a small business under the applicable NAICS code should not submit a response to this notice. Small businesses concerns shall be capable of provide the necessary equipment and personnel to furnish service in the volume required for all the items under this contract. Contractor shall meet all requirements of Federal, State or City codes regarding operations of this type of service. The NAICS code is 334290 DESCRIPTION OF THE REQUIREMENT: Radio Communication between the Carroll County Sheriff's Department, local Law Enforcement agencies and the United States Department of Veterans Affairs Police using the West Georgia Regional Radio System. 2. Scope of Work: West Georgia Regional Radio System will make the Department of Veterans Affairs Police a tenant on the system for a one time cost of $XXXX.00 There is also a Subscriber cost which is$ XXXX.00 per unit per year. The Subscriber cost covers any maintenance or service to the system. This procurement MAY involve licensed, proprietary software, software upgrades and proprietary passwords. Please indicate if you can provide the equipment, installation services as well as training for medical staff using the equipment CONTRACT AWARD MEETING The contractor shall not commence performance on the tasks in this SOW until the Contracting Officer has conducted a kick off meeting or has advised the contractor that a kick off meeting is waived. 1. For every task, the contractor shall identify in writing all necessary subtasks (if any), associated costs by task, and together with associated submilestone dates. The contractor's subtask structure shall be reflected in the technical proposal and detailed work plan. 2. All written deliverables shall be phrased in layperson language. Statistical and other technical terminology shall not be used without providing a glossary of terms. 1. The contractor shall complete the Delivery Date column in Attachment A for each deliverable specified. 2. Unless otherwise specified, the number of draft copies and the number of final copies shall be the same. 3. If for any reason any deliverable cannot be delivered within the scheduled time frame, the contractor is required to explain why in writing to the Contracting Officer, including a firm commitment of when the work shall be completed. This notice to the Contracting Officer shall cite the reasons for the delay, and the impact on the overall project. The Contracting Officer will then review the facts and issue a response in accordance with applicable regulations. Site NameSite Type (Main or Remote)Address VA CarrolltonRemote 180 Martin Dr, Carrollton, GA 30117
- Web Link
-
FBO.gov Permalink
(https://www.fbo.gov/spg/VA/AtlVAMC/VAMCCO80220/VA24712I1056/listing.html)
- Document(s)
- Attachment
- File Name: VA247-12-I-1056 VA247-12-I-1056.docx (https://www.vendorportal.ecms.va.gov/FBODocumentServer/DocumentServer.aspx?DocumentId=455818&FileName=VA247-12-I-1056-000.docx)
- Link: https://www.vendorportal.ecms.va.gov/FBODocumentServer/DocumentServer.aspx?DocumentId=455818&FileName=VA247-12-I-1056-000.docx
- Note: If links are broken, refer to Point of Contact above or contact the FBO Help Desk at 877-472-3779.
- File Name: VA247-12-I-1056 VA247-12-I-1056.docx (https://www.vendorportal.ecms.va.gov/FBODocumentServer/DocumentServer.aspx?DocumentId=455818&FileName=VA247-12-I-1056-000.docx)
- Place of Performance
- Address: CARROLLTON VA MEDICAL CLINIC;180 Martin Drive;Carrollton, GA
- Zip Code: 30117
- Zip Code: 30117
- Record
- SN02854185-W 20120826/120824235851-2bddd838ba71278859fcfdbb39fedf0d (fbodaily.com)
- Source
-
FedBizOpps Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |