SOURCES SOUGHT
Y -- AIRFIELD REPAIRS NAVAL AIR STATION JOINT RESERVE BASE FT WORTH, TX
- Notice Date
- 12/20/2012
- Notice Type
- Sources Sought
- NAICS
- 237310
— Highway, Street, and Bridge Construction
- Contracting Office
- N69450 NAVFAC Southeast, Southeast Bldg. 903 Building 903 P. O. Box 30 NAS Jacksonville Jacksonville, FL
- ZIP Code
- 00000
- Solicitation Number
- N6945013RSS99
- Response Due
- 1/9/2013
- Archive Date
- 1/9/2015
- Point of Contact
- Mark VanLuit (904)542-6337
- Small Business Set-Aside
- N/A
- Description
- Sources sought for a construction contract for Airfield Repairs at NAS JRB Fort Worth, TX. THIS IS A SOURCES SOUGHT ANNOUNCEMENT, A MARKET SURVEY FOR WRITTEN INFORMATION ONLY. THIS IS NOT A SOLICITATION ANNOUNCEMENT FOR PROPOSALS AND NO CONTRACT WILL BE AWARDED FROM THIS ANNOUNCEMENT. NO REIMBURSEMENT WILL BE MADE FOR ANY COSTS ASSOCIATED WITH PROVIDING INFORMATION IN RESPONSE TO THIS ANNOUNCEMENT OR ANY FOLLOW-UP INFORMATION REQUESTS. THE GOVERNMENT WILL USE RESPONSES TO THIS SOURCES SOUGHT ANNOUNCEMENT TO MAKE APPROPRIATE ACQUISITION DECISIONS. No telephone calls will be accepted requesting a bid package or solicitation. There is no bid package or solicitation. In order to protect the procurement integrity of any future procurement, if any, that may arise from this announcement, information regarding the technical point of contact will not be given and no appointments for presentations will be made. The Naval Facilities Engineering Command Southeast (NAVFAC SE) is seeking qualified and interested parties in any of the following categories: U.S. Small Business Administration (SBA) certified 8(a), HUBZone Small Business (HUBZone), Service Disabled Veteran-Owned Small Business (SDVOSB), Veteran-Owned Small Business and/or Small Business (SB) sources with current relevant qualifications, experience, personnel, and capability to perform. The proposed project will repair the airfield at Naval Air Station (NAS) Joint Reserve Base (JRB) Fort Worth, TX. The contract will be for a term of between one year and two years. The estimated cost for this project is between $3,000,000 and $5,000,000. The North American Industry Classification System (NAICS) Code is 237310 with a Small Business Size Standard of $33.5 million. The Government invites contractors with the capabilities necessary to meet or exceed the stated requirements to submit Capability Statements consisting of appropriate documentation, literature, brochures, and references anticipated to be five to ten pages, following the set format. Respondents must include references and a capability statement for at least two completed projects within the last seven years that are similar to the construction work and of similar size, scope and complexity (adjusted for inflation) of this notice. Each reference shall include the company name and title, telephone number, email address and point of contact. Provide evidence of sufficient available bonding capacity with the name of bonding company, telephone number, email address and point of contact. The capability statements for each project shall be numbered and include the below requirements and supporting documentation. Respondents shall provide a list of projects by contract numbers, project titles, dollar amounts, project completion dates, performance ratings and evidence of capability to complete the following contract requirements: This project location is at NAS JRB Fort Worth, TX. The construction project involves mill and overlay of the asphalt portion of the runway. Work will include milling of 2-inches of surface pavement; asphalt overlay of approximately 2-inches in thickness, and restriping of markings within the asphalt area and adjacent concrete pavement. Total area of asphalt mill and overlay is approximately 162,000 square yards. Additionally, and what will be proposed as a contract option, the existing asphalt shoulder of taxiway Foxtrot will be milled and overlaid to correct a deficient surface condition with restriped taxiway edge markings. The contractors must include the following information: 1. Provide company information to include name, address, phone number, email address and DUNS number. 2. Identify whether your firm is a self-certified Small Business or SDVOSB, or an SBA certified 8 (a) or HUBZone firm. If you are an 8(a) or HUBZone firm, provide proof of SBA certification. If you are submitting as a mentor-protégé joint venture under the 8(a) program, you must provide SBA approval of the mentor-protégé agreement to be considered as small for this procurement. For more information on the definition or requirements for these, refer to http://www.sba.gov/. 3. Provide a minimum of two completed airfield pavement projects as the prime contractor within the last seven years of similar size (value of approximately $3.5 million or greater), scope and complexity as the work indicated above. Provide project specifics and demonstrate how each project is relevant to the proposed construction project. Provide references with names, email and postal addresses, and phone numbers. 4. Bonding Capacity: Provide surety ™s name, telephone number and point of contact, your maximum bonding capacity per project, and your maximum aggregate bonding. The Capabilities Statement for this sources sought is not expected to be a proposal, but rather short statements regarding the company ™s ability to demonstrate existing-or-developed expertise and experience in relation to the areas specified herein. Any commercial brochures or currently existing marketing material may also be submitted with the Capabilities statement. Submission of Capabilities statement is not a prerequisite to any potential future offerings, but participation will assist the Government in tailoring requirements to be consistent with industry capabilities. After completing its analysis, the Government will determine whether to limit competition among 8(a), HubZone, SDVOSB, Veteran-Owned Small Business and/or Small Business firms or to proceed with issuing an unrestricted solicitation, inviting full and open competition. Please respond to this announcement by 2:00 PM eastern time on 09 January 2013 via email to mark.vanluit@navy.mil. The subject line of the email shall read: Airfield Repairs, NAS JRB Fort Worth, Texas. Responses that do not meet all requirements or submitted within the allotted time will not be considered. Respondents will not be notified of the results of the evaluation.
- Web Link
-
FBO.gov Permalink
(https://www.fbo.gov/notices/69ac35d2bef5f39bc937580dfd1b0fcc)
- Record
- SN02952919-W 20121222/121220234543-69ac35d2bef5f39bc937580dfd1b0fcc (fbodaily.com)
- Source
-
FedBizOpps Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |