MODIFICATION
Z -- HOME REPAIRS DR4339PR PUERTO RICO
- Notice Date
- 10/12/2018
- Notice Type
- Modification/Amendment
- Contracting Office
- 3003 Chamblee Tucker Rd, atlanta, GA 30341
- ZIP Code
- 30341
- Solicitation Number
- 70FBR218I00000003-01
- Response Due
- 10/16/2018
- Archive Date
- 4/14/2019
- Point of Contact
- Name: Client Services, Title: Client Services, Phone: 1.877.933.3243, Fax: 703.422.7822
- E-Mail Address
-
Clientservices@fedbid.com;
- Small Business Set-Aside
- N/A
- Description
- MODIFICATION NOTICE: Bids are being solicited under solicitation number 70FBR218I00000003-01. This announcement constitutes the only solicitation; bids are being requested and a written solicitation will not be issued. The solicitation is issued as an invitation for bids (IFB), unless otherwise indicated herein.If your company can provide the product/services listed on the solicitation and comply with all of the solicitation instructions, please respond to this notice. To view the specifications, please go to www.FedBid.com and reference Buy No. 938304_04. IDIQ: Sellers bidding on this opportunity MUST have the items requested on the specified contract. The contract must either be in the Seller's name or the Seller must be able to document its ability to act as an agent of a partner's contract. Sellers may offer Open Market items only in accordance with the approved Terms and Conditions of their respective contract AND approval from the soliciting contracting officer. This requirement is a [ Small Business ] set-aside and only qualified offerors may submit bids.The solicitation pricing on www.FedBid.com will start on the date this solicitation is posted and will end on 2018-10-16 17:00:00.0 Eastern Time or as otherwise displayed at www.FedBid.com.FOB Destination shall be in the Statement of Work.. The DHS Federal Emergency Management Agency requires the following items, Purchase Description Determined by Line Item, to the following: LI 001: REPAIR HOMES PER ATTACHED STATEMENT OF OBJECTIVES. THIS IS THE FIXED PRICE PORTION INCLUSIVE OF DIRECT LABOR, MATERIALS, TRANSPORTATION, MANAGEMENT TO COMPLETE THE REPAIRS. FOR PURPOSES OF THIS SOLICITATION ENTER A PRICE OF $100,000.00/EA FOR THIS LINE ITEM. THIS IS ROUGHLY THE PROGRAM CAP PER HOME. CONTRACT AWARD WILL NOT BE MADE BASED ON THIS PRICE. CONTRACT AWARD WILL BE BASED ON IDENTIFYING BEST QUALIFIED COMPANY OR COMPANIES FOR THIS PROCUREMENT. FEMA MAY AWARD ONE OR MORE CONTRACTS FOR THIS REQUIREMENT. ACTUAL PRICE OF REPAIRS WILL BE BASED ON SPECIFIC QUOTE PER HOME. IMPORTANT TO READ ENTIRE SOO ATTACHED. Government is only identifying best qualified companies at this time, and price is not a evaluation factor., 50, EA; LI 002: MISCELLANEOUS COSTS TO INCLUDE PERMITTING. THIS IS A COST-REIMBURSEMENT AMOUNT THAT THE GOVERNMENT WILL FUND BASED ON PRE-APPROVED ACTUAL COSTS. FOR PURPOSES OF THIS SOLICITATION ENTER A PRICE OF $25,000.00 / EA FOR THIS LINE ITEM BASED ON PROGRAM CAP PER HOME. CONTRACT AWARD WILL NOT BE MADE BASED ON THIS PRICE. CONTRACT AWARD WILL BE BASED ON IDENTIFYING BEST QUALIFIED COMPANY OR COMPANIES FOR THIS PROCUREMENT. FEMA MAY AWARD ONE OR MORE CONTRACTS FOR THIS REQUIREMENT. ACTUAL REIMBURSEABLE AMOUNT WILL BE BASED ON SPECIFIC COSTS PER HOME. IMPORTANT TO READ ENTIRE SOO ATTACHED. Government is only identifying best qualified companies at this time, and price is not a evaluation factor. This line item is for permits and contingencies that may impact the repair of the structure for example soil remediation, asbestos removal, etc., 50, EA; Solicitation and Buy Attachments ***Question Submission: Interested offerors must submit any questions concerning the solicitation at the earliest time possible to enable the Buyer to respond. Questions must be submitted by using the 'Submit a Question' feature at www.fedbid.com. Questions not received within a reasonable time prior to close of the solicitation may not be considered.*** For this solicitation, DHS Federal Emergency Management Agency intends to conduct an online competitive reverse auction to be facilitated by the third-party reverse auction provider, FedBid, Inc. FedBid has developed an online, anonymous, browser based application to conduct the reverse auction. A Seller may submit a series of pricing bids, which descend in price during the specified period of time for the aforementioned reverse auction. DHS Federal Emergency Management Agency is taking this action in an effort to improve both seller access and awareness of requests and the agency's ability to gather multiple, completed, real-time bids.All responsible Sellers that respond to this solicitation MUST submit the pricing portion of their bid using the online exchange located at www.FedBid.com. There is no cost to register, review procurement data or make a bid on www.FedBid.com.Sellers that are not currently registered to use www.FedBid.com should proceed to www.FedBid.com to complete their free registration. Sellers that require special considerations or assistance may contact the FedBid Helpdesk at 877-9FEDBID (877-933-3243) or via email at clientservices@fedbid.com. Sellers may not artificially manipulate the price of a transaction on www.FedBid.com by any means. It is unacceptable to place bad faith bids, to use decoys in the www.FedBid.com process or to collude with the intent or effect of hampering the competitive www.FedBid.com process.Should Sellers require additional clarification, contact FedBid at 877-9FEDBID (877-933-3243) or clientservices@fedbid.com. Use of FedBid: Buyers and Sellers agree to conduct this transaction through FedBid in compliance with the FedBid Terms of Use. Failure to comply with the below terms and conditions may result in offer being determined as non-responsive. New Equipment ONLY; NO remanufactured or "gray market" items. All items must be covered by the manufacturer's warranty. Bid MUST be good for 30 calendar days after close of Buy. This solicitation requires registration with the System for Award Management (SAM) prior to award, pursuant to applicable regulations and guidelines. Registration information can be found at www.sam.gov. The selected Offeror must comply with the following terms and conditions, which are incorporated herein by reference: 52.236-2, Differing Site Conditions 52.236-3, Site Investigation and Conditions Affecting the Work 52.236-5, Material and Workmanship 52.243-4 “ Changes 52.236-6, Superintendence by the Contractor 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements 52.236-11, Use and Possession Prior to Completion 52.246-12, Inspection of Construction 52.236-5, Material and Workmanship 52.236-7, Permits and Responsibilities 52.236-8, Other Contracts, 52.236-10, Operations and Storage Areas. 52.236-12, Cleaning Up 52.236-14, Availability and Use of Utility Services 52.236-15, Schedules for Construction Contracts 52.236-16, Quantity Surveys 52.225-9 Buy American ”Construction Materials. 52.232-5, Payments under FP Construction Contracts 52.232-27, Prompt Payment under Construction Contracts 52.246-21, Warranty of Construction 52.236-5, Material and Workmanship 52.246-12, Inspection of Construction 52.211-12, Liquidated Damages, Construction 52.211-18, Variation in Estimated Quantity - Construction 52.236-4, Physical Data 52.236-7, Permits and Responsibilities 52.236-9, Protection of Existing... 52.236-13, Accident Prevention 52.211-10, Commencement, Prosecution, & completion of work 52.211-13 Time Extensions 52.228-3 “ Workers ™ Compensation Insurance (Defense Base Act) Shipping must be free on board (FOB) destination PUERTO RICO which means that the seller must deliver the goods on its conveyance at the destination specified by the buyer, and the seller is responsible for the cost of shipping and risk of loss prior to actual delivery at the specified destination. Proposals will only be considered from Puerto-Rico-based bidders residing within disaster declaration DR4339PR PUERTO RICO as defined by FAR 52.226-3c. If the offeror does not meet representation criteria of FAR 52.226-3c, he shall furnish documentation to support its representation IAW FAR 52.226-3D AND PROVIDE THAT IN HIS PROPOSAL ATTACHMENT. FAR 52.211-12 “ Liquidated Damages ”Construction (Sept 2000) (a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $100 PER DAY FOR EACH WORK ORDER for each calendar day of delay until the work is completed or accepted. (b) If the Government terminates the Contractor ™s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause. FAR 52.211-13 Time Extensions. Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.
- Web Link
-
FBO.gov Permalink
(https://www.fbo.gov/spg/DHS/FEMA/PP5-2/70FBR218I00000003-01/listing.html)
- Place of Performance
- Address: See Statement of Work.
- Zip Code: -
- Zip Code: -
- Record
- SN05121995-W 20181014/181012230354-d0fa6c56715bc5da38080ff5afbefd19 (fbodaily.com)
- Source
-
FedBizOpps Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |