U. S. ARMY ENGINEER DISTRICT, MOBILE, ATTN: CESAM-CT (PLANS ROOM NO. 1000A), P. O. BOX 2288 MOBILE ALABAMA 36628-0001, OR 109 ST. JOSEPH STREET MOBILE AL 36602

Y -- WAREHOUSE MOISTURE MIGRATION, MEMPHIS DEFENSE DEPOT, TN SOL DACA01-97-B-0090 DUE 090897 POC Contact Karen Johnson (334)690-2535 Contracting Officer, Gene L. Curtis (Site Code W31XNJ) Work involves painting 6 Korean war vintage block warehouses, including sweep blasting each warehouse (200'x1,000'x25'). Bid documents are available on or about 6 August 1997. Estimated cost of work is between $500,000 to $1,000,000. Requests for plans and specifications shall indicate in writing whether firm will bid as a prime contractor or subcontractor. Bidders, subcontractors and Dodge/Plan Rooms are encouraged to register on the Internet to receive one free CD-ROM. Registration on the Internet should minimize possible errors and delay in receiving the CD- ROM. Registration instructions are available on the Internet at http://www.sam.usace.army.mil/sam/ct. Registration may also be completed by faxing to 334-694-4343, Attn: PlansRoom, CESAM. Telephonic requests will not be accepted. In either case, those registering are responsible for the accuracy of the information on the mailing list. Registration must include the firms physical address, telephone, fax number and a point of contact. Registrationshould be completed one week prior to the issue date. All notifications of changes to this solicitation shall be made through the Internet only. It is therefore the contractors responsibility to check the Internet address listed above daily, for any posted changes to this solicitation. Actual solicitation amendments will be issued either by fax, 3.5" diskette or CD-ROM. The plans and specifications will be issued on Compact Disc (CD-ROM) only and will be provided free of charge. Plans and specifications will not be provided in a printed paper format; however, the Government reserves the right to revert to paper medium when it is determined to be in the Government's best interest. All bid forms, bid bonds, and other normal documents required for the bid submittal, including amendments to the bid submittal, shall be in paper medium. Electronic medium for the bid submittal documents will not be allowed. Critical path method (Network Analysis System) is required. For this job, a small business is defined as having average annual receipts of less than $17,000,000 for the past three years. Specific questions related to this project may be answered by Carol Conklin at 334-694-3605, fax 334-690-2902. Refer questions on distribution of plans/specifications to the PlansRoom 334-690-2535. Unrestricted. All responsible sources may submit a bid (0197)

Loren Data Corp. http://www.ld.com (SYN# 0169 19970718\Y-0033.SOL)